Terms of Service

Effective Date: June 2, 2026

Welcome to AquaCraft Docks & Seawalls ("Company," "we," "our," or "us"). These Terms of Service ("Terms") govern your use of our website, services, estimates, communications, and related interactions with AquaCraft Docks & Seawalls.

By accessing our website, requesting an estimate, scheduling services, or engaging with AquaCraft Docks & Seawalls, you agree to be bound by these Terms.

Services

AquaCraft Docks & Seawalls provides marine construction and waterfront improvement services, including but not limited to:

• Dock construction and replacement
• Seawall construction and repair
• Boat lifts and boat houses
• Boardwalks and walkways
• Pavilions and waterfront structures
• Dune crossings
• Shoreline stabilization
• Marine piling installation
• Dock repairs and maintenance
• Waterfront permitting assistance
• Other related marine construction services

Estimates and Proposals

All estimates are based upon information available at the time of inspection and may be subject to change.

Factors that may impact pricing include:

• Subsurface conditions
• Water depth variations
• Environmental regulations
• Permit requirements
• Utility conflicts
• Material availability
• Changes requested by the customer
• Unforeseen site conditions

Written estimates are valid for 30 days unless otherwise stated.

Deposits and Payments

Projects may require a deposit before scheduling or ordering materials.

Payment schedules will be outlined within the project proposal, contract, or invoice.

Accepted payment methods may include:

• Credit cards
• ACH transfers
• Checks
• Other approved payment methods

Late payments may be subject to finance charges, collection costs, attorney fees, and other remedies permitted by law.

Permits and Regulatory Approvals

Many marine construction projects require permits from local, county, state, or federal agencies.

Permit timelines are outside the control of AquaCraft Docks & Seawalls and may impact project schedules.

Unless otherwise specified in writing, customers remain responsible for:

• Property ownership verification
• Easement restrictions
• HOA approvals
• Environmental compliance requirements
• Boundary and survey verification

AquaCraft Docks & Seawalls is not responsible for delays caused by permitting agencies or regulatory reviews.

Scheduling and Project Timelines

Project schedules are estimates only and are not guaranteed.

Completion dates may be affected by:

• Weather conditions
• Tidal and water conditions
• Permit approvals
• Material availability
• Environmental restrictions
• Utility conflicts
• Labor availability
• Circumstances beyond our reasonable control

We will make reasonable efforts to keep customers informed regarding project scheduling and status.

Site Access and Customer Responsibilities

Customers agree to provide reasonable access to the project site.

Customers are responsible for:

• Identifying known property boundaries
• Providing access to the waterfront work area
• Removing personal property from construction zones
• Identifying known underground utilities, irrigation systems, or private infrastructure
• Securing pets and personal belongings

AquaCraft Docks & Seawalls is not responsible for delays caused by restricted access or undisclosed site conditions.

Warranty

AquaCraft Docks & Seawalls provides workmanship warranties as outlined in the applicable project agreement.

Manufacturer warranties for materials, lifts, pilings, decking, hardware, and related products are provided directly by the manufacturer and subject to their terms.

Warranty coverage does not apply to:

• Hurricanes
• Tropical storms
• Flooding
• Erosion
• Vessel impacts
• Acts of nature
• Improper use
• Unauthorized modifications
• Normal wear and tear
• Damage caused by third parties

Limitation of Liability

To the fullest extent permitted by law, AquaCraft Docks & Seawalls shall not be liable for indirect, incidental, special, consequential, or punitive damages arising from the use of our website or services.

Our total liability for any claim relating to services provided shall not exceed the amount paid by the customer for the specific project giving rise to the claim.

Website Use

You agree not to:

• Use the website for unlawful purposes
• Attempt unauthorized access to website systems
• Upload malicious software or code
• Interfere with website operations
• Misrepresent your identity when submitting forms

Communications

By submitting a form, requesting information, scheduling services, or providing contact information, you consent to receive communications from AquaCraft Docks & Seawalls, including:

• Phone calls
• Emails
• Text messages
• Appointment reminders
• Project updates
• Estimate notifications
• Invoices and service communications

Message frequency may vary.

Message and data rates may apply.

You may opt out of marketing communications at any time. Transactional and project-related communications may continue as necessary to complete contracted services.

Intellectual Property

All content on this website, including text, graphics, images, logos, videos, designs, and branding, is the property of AquaCraft Docks & Seawalls and may not be copied, reproduced, distributed, or used without written permission.

Indemnification

You agree to indemnify and hold harmless AquaCraft Docks & Seawalls, its owners, employees, contractors, affiliates, and representatives from any claims, losses, liabilities, damages, or expenses arising from your use of our website or violation of these Terms.

Force Majeure

AquaCraft Docks & Seawalls shall not be liable for delays or failure to perform due to circumstances beyond our reasonable control, including but not limited to:

• Hurricanes
• Tropical storms
• Flooding
• Severe weather
• Natural disasters
• Material shortages
• Labor shortages
• Government actions
• Regulatory delays
• Utility conflicts
• Supply chain disruptions

Governing Law

These Terms shall be governed by and construed in accordance with the laws of the State of Florida.

Any legal action arising from these Terms shall be brought in a court of competent jurisdiction within the State of Florida.

Changes to These Terms

We reserve the right to update or modify these Terms at any time. Updated versions will be posted on this page with a revised effective date.

Contact Information

AquaCraft Docks & Seawalls

Website: aquacraftdocks.com

Phone: 321-479-5309

Serving Central Florida and Florida's Eastern Coastline

By using this website or engaging AquaCraft Docks & Seawalls for services, you acknowledge that you have read, understood, and agree to these Terms of Service.

Proudly Serving Central Florida and the Surrounding Coastal Communities

At AquaCraft, we provide professional marine and watercraft services throughout Central Florida and nearby coastal areas. From Orlando and surrounding inland cities to Daytona Beach, New Smyrna Beach, Merritt Island, and Palm Bay, our team delivers reliable, high-quality service wherever your boat is located—so you can spend less time worrying about maintenance and more time on the water.

• Altamonte Springs
• Apopka
• Belle Isle
• Caselberry
• Clermont
• Deland
• Edgewood
• Isleworth
• Lake Mary
• Lake Nona
• Longwood
• Maitland
• Monteverde
• Oakland
• Ocoee
• Orange County
• Oviedo
• Sanford
• Seminole County
• Windermere
• Winter Garden
• Winter Park
• Winter Springs
• Daytona Beach
• New Smyrna Beach
• Merritt Island
• Palm Bay